Vilkår og betingelser

Business Day: a day other than a Saturday, Sunday or public holiday in England, when banks in London are open for business.

Business Hours: the period from 9.00 am to 5.00 pm on any Business Day.

Conditions: the terms and conditions set out in this document as amended from time to time in accordance with clause 11.4.

Contract: the contract between the Supplier and the Customer for the sale and purchase of the Goods in accordance with these Conditions.

Customer: the business or other entity that purchases the Goods from the Supplier.

Force Majeure Event: an event, circumstance or cause beyond a party's reasonable control.

Goods: the goods (or any part of them) set out in the Order.

Order: the Customer's order for the Goods, as set out in the Customer's purchase order form, the Customer's acceptance of the Supplier's quotation, or overleaf, as the case may be.

Specification: any specification for the Goods as specified in an applicable Order.

Supplier: DWIR Limited (registered in England and Wales with company number 12688528) trading as Omni Group.

1.1. A person includes a natural person, corporate or unincorporated body (whether or not having separate legal personality).

1.2 A reference to a party includes its successors and permitted assigns.

1.3 A reference to legislation or a legislative provision is a reference to it as amended or re-enacted. A reference to legislation or a legislative provision includes all subordinate legislation made under that legislation or legislative provision.

1.4 Any words following the terms including, include, in particular, for example or any similar expression shall be interpreted as illustrative and shall not limit the sense of the words preceding those terms.

1.5 A reference to writing or written excludes fax and email.

4.1 The Supplier shall ensure that each delivery of the Goods is accompanied by a delivery note that shows the date of the Order, all relevant Supplier reference numbers, and the type and quantity of the Goods.

4.2 The Supplier shall deliver the Goods to the location set out in the Order or such other location as the parties may agree (Delivery Location) at any time after the Supplier notifies the Customer that the Goods are ready.

4.3 Delivery is completed on the completion of unloading of the Goods at the Delivery Location.

4.4 Any dates quoted for delivery are approximate only, and the time of delivery is not of the essence. The Supplier shall not be liable for any delay in delivery of the Goods that is caused by a Force Majeure Event or the Customer's failure to provide the Supplier with adequate delivery instructions or any other instructions that are relevant to the supply of the Goods.

4.5 If the Supplier fails to deliver the Goods, its liability shall be limited to the costs and expenses incurred by the Customer in obtaining replacement goods of similar description and quality in the cheapest market available, less the price of the Goods. The Supplier shall have no liability for any failure to deliver the Goods to the extent that such failure is caused by a Force Majeure Event or the Customer's failure to provide the Supplier with adequate delivery instructions or any other instructions that are relevant to the supply of the Goods.

4.6 If the Customer fails to take delivery of the Goods within 3 (three) Business Days of the Supplier notifying the Customer that the Goods are ready, then, except where such failure or delay is caused by a Force Majeure Event or the Supplier's failure to comply with its obligations under the Contract in respect of the Goods:

(a) delivery of the Goods shall be deemed to have been completed at 9.00 am on the third Business Day after the day on which the Supplier notified the Customer that the Goods were ready; and

(b) the Supplier shall store the Goods until actual delivery takes place and charge the Customer for all related costs and expenses (including insurance).

4.7 If 10 (ten) Business Days after the day on which the Supplier notified the Customer that the Goods were ready for delivery the Customer has not taken actual delivery of them, the Supplier may charge the Customer storage costs equal to 5% of the total Order cost including taxes for each period of 5 working days that the Goods remain stored.

4.8 The Supplier may deliver the Goods by instalments, which shall be invoiced and paid for separately. Each instalment shall constitute a separate contract. Any delay in delivery or defect in an instalment shall not entitle the Customer to cancel any other instalment.

4.9 If delivery cannot be completed on the arranged date due to refusal by the Customer, this is deemed a failed installation. The Supplier will charge the Customer the full installation fee as detailed on the relevant invoice.

4.10 Delivery cannot be re-scheduled by the Customer later than 48 hours before the scheduled delivery date. If the Customer requests a change to the delivery schedule later than 48 hours before the scheduled delivery date, the Supplier will charge the Customer an administration fee of 10% of the total Order value including taxes.

5.1 The Supplier warrants that on delivery, and for (i) a period of 60 months from the date of delivery in respect of the external frame, (ii) a period of 24 months from the date of delivery in respect of any electrical parts, and (iii) a period of 12 months in respect of all and any other component parts (in each case respectively the Warranty Period), the Goods shall:

(a) conform in all material respects with their description and any applicable Specification;

(b) be free from material defects in design, material and workmanship; and

(c) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979).

5.2 Subject to clause 5.3, if:

(a) the Customer gives notice in writing to the Supplier during the Warranty Period within a reasonable time of discovery that some or all of the Goods do not comply with the warranty set out in clause 5.1;

(b) the Supplier is given a reasonable opportunity of examining such Goods; and

(c) the Customer (if asked to do so by the Supplier) returns such Goods to the Supplier's place of business at the Customer's cost,

the Supplier shall, at its option, repair or replace the defective Goods (or relevant defective part(s) of them), or refund the price of the defective Goods in full.

5.3 The Supplier shall not be liable for the Goods' failure to comply with the warranty set out in clause 5.1 if:

(a) the Customer makes any further use of such Goods after giving notice in accordance with clause 5.2;

(b) the defect arises because the Customer failed to follow the Supplier's oral or written instructions as to the storage, commissioning, installation, use and maintenance of the Goods or (if there are none) good trade practice regarding the same;

(c) the defect arises as a result of the Supplier following any drawing, design or specification supplied by the Customer;

(d) the Customer alters or repairs such Goods without the written consent of the Supplier;

(e) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal storage or working conditions; or

(f) the Goods differ from their description and any applicable Specification as a result of changes made to ensure they comply with applicable statutory or regulatory requirements.

5.4 Except as provided in this clause 5, the Supplier shall have no liability to the Customer in respect of the Goods' failure to comply with the warranty set out in clause 5.1.

5.5 The terms implied by sections 13 to 15 of the Sale of Goods Act 1979 are, to the fullest extent permitted by law, excluded from the Contract.

5.6 These Conditions shall apply to any repaired or replacement Goods supplied by the Supplier.

6.1 Subject to clause 6.2, the risk in the Goods shall pass to the Customer on completion of delivery.

6.2 Title to the Goods shall not pass to the Customer until the Supplier receives payment in full (in cash or cleared funds) for the Goods.

6.3 Until title to the Goods has passed to the Customer, the Customer shall:

(a) store the Goods separately from all other goods held by the Customer so that they remain readily identifiable as the Supplier's property;

(b) not remove, deface or obscure any identifying mark or packaging on or relating to the Goods;

(c) maintain the Goods in satisfactory condition and keep them insured against all risks for their full price from the date of delivery;

(d) notify the Supplier immediately if it becomes subject to any of the events listed in clause 9.1(b) to clause 9.1(d); and

(e) give the Supplier such information as the Supplier may reasonably require from time to time relating to:

(i) the Goods; and

(ii) the ongoing financial position of the Customer.

6.4 At any time before title to the Goods passes to the Customer, the Supplier may require the Customer to deliver up all Goods in its possession and, if the Customer fails to do so promptly, enter any premises of the Customer or of any third party where the Goods are stored in order to recover them.

7.1 The price of the Goods shall be the price set out in the Order or, if no price is quoted, the price set out in the Supplier's published price list in force as at the date of delivery. All prices are quoted in GBP unless otherwise stated.

7.2 The Supplier may, by giving notice to the Customer at any time up to 5 (five) Business Days before delivery, increase the price of the Goods to reflect any increase in the cost of the Goods that is due to:

(a) any factor beyond the Supplier's control (including foreign exchange fluctuations, increases in taxes and duties, and increases in labour, materials and other manufacturing costs);

(b) any request by the Customer to change the delivery date(s), quantities or types of Goods ordered, or the Specification; or

(c) any delay caused by any instructions of the Customer or failure of the Customer to give the Supplier adequate or accurate information or instructions.

7.3 The price of the Goods:

(a) excludes amounts in respect of value added tax (VAT), which the Customer shall additionally be liable to pay to the Supplier at the prevailing rate, subject to the receipt of a valid VAT invoice; and

(b) excludes the costs and charges of packaging, insurance, transport and installation (where applicable) of the Goods, which shall be invoiced to the Customer.

7.4 Save as otherwise agreed in writing by the Supplier, payment for the Goods must be made in advance of delivery as detailed within the Order, to the bank account nominated in writing by the Supplier. Time for payment shall be of the essence of the Contract.

7.5 If the Customer fails to make a payment due to the Supplier under the Contract by the due date, then, without limiting the Supplier's remedies under clause 9, the Customer shall pay interest on the overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause 7.5 will accrue each day at 4% a year above the Bank of England's base rate from time to time, but at 4% a year for any period when that base rate is below 0%, and the Supplier may suspend delivery of the Goods until payment has been made in full.

7.6 All amounts due under the Contract shall be paid in full without any set-off, counterclaim, deduction or withholding (other than any deduction or withholding of tax as required by law).

8.1 References to liability in this clause 8 include every kind of liability arising under or in connection with the Contract including liability in contract, tort (including negligence), misrepresentation, restitution or otherwise.

8.2 Nothing in the Contract limits any liability which cannot legally be limited, including liability for:

(a) death or personal injury caused by negligence;

(b) fraud or fraudulent misrepresentation;

(c) breach of the terms implied by section 12 of the Sale of Goods Act 1979; or

(d) defective products under the Consumer Protection Act 1987.

8.3 Subject to clause 8.2, the Supplier's total liability to the Customer under this Contract shall not exceed the total price of the Goods.

8.4 Subject to clause 8.2, the following types of loss are wholly excluded:

(a) loss of profits;

(b) loss of sales or business;

(c) loss of agreements or contracts;

(d) loss of anticipated savings;

(e) loss of use or corruption of software, data or information;

(f) loss of or damage to goodwill; and

(g) indirect or consequential loss.

8.5 This clause 8 shall survive termination of the Contract.

9.1 Without limiting its other rights or remedies, the Supplier may terminate this Contract with immediate effect by giving written notice to the Customer if:

(a) the Customer commits a material breach of any term of the Contract and (if such a breach is remediable) fails to remedy that breach within 10 (ten) Business Days of being notified in writing to do so;

(b) the Customer takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), obtaining a moratorium, being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business or, if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction;

(c) the Customer suspends, threatens to suspend, ceases or threatens to cease to carry on all or a substantial part of its business; or

(d) the Customer's financial position deteriorates so far as to reasonably justify the opinion that its ability to give effect to the terms of the Contract is in jeopardy.

9.2 Without limiting its other rights or remedies, the Supplier may suspend provision of the Goods under the Contract or any other contract between the Customer and the Supplier if the Customer becomes subject to any of the events listed in clause 9.1(b) to clause 9.1(d), or the Supplier reasonably believes that the Customer is about to become subject to any of them, or if the Customer fails to pay any amount due under this Contract on the due date for payment.

9.3 Without limiting its other rights or remedies, the Supplier may terminate the Contract with immediate effect by giving written notice to the Customer if the Customer fails to pay any amount due under the Contract on the due date for payment.

9.4 On termination of the Contract for any reason the Customer shall immediately pay to the Supplier all of the Supplier's outstanding unpaid invoices and interest and, in respect of Goods supplied but for which no invoice has been submitted, the Supplier shall submit an invoice, which shall be payable by the Customer immediately on receipt.

9.5 Termination or expiry of the Contract, however arising, shall not affect any of the parties' rights and remedies that have accrued as at termination or expiry, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination or expiry.

9.6 Any provision of the Contract that expressly or by implication is intended to come into or continue in force on or after termination or expiry of the Contract shall remain in full force and effect.

10.1 Neither party shall be in breach of the Contract or otherwise liable for any failure or delay in the performance of its obligations if such delay or failure results from a Force Majeure Event. The time for performance of such obligations shall be extended accordingly. If the period of delay or non-performance continues for 4 (four) months, the party not affected may terminate the Contract by giving 30 days' written notice to the affected party.

11.1 Assignment and other dealings

(a) The Supplier may at any time assign, transfer, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with all or any of its rights or obligations under the Contract.

(b) The Customer may not assign, transfer, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any or all of its rights or obligations under the Contract without the prior written consent of the Supplier.

11.2 Confidentiality

(a) Each party undertakes that it shall not at any time during the Contract, and for a period of two years after termination or expiry of the Contract, disclose to any person any confidential information concerning the business, assets, affairs, customers, clients or suppliers of the other party, except as permitted by clause 11.2(b).

(b) Each party may disclose the other party's confidential information:

(i) to its employees, officers, representatives, contractors, subcontractors or advisers who need to know such information for the purposes of exercising the party's rights or carrying out its obligations under the Contract. Each party shall ensure that its employees, officers, representatives, contractors, subcontractors or advisers to whom it discloses the other party's confidential information comply with this clause 11.2; and

(ii) as may be required by law, a court of competent jurisdiction, or any governmental or regulatory authority.

(c) Neither party shall use the other party's confidential information for any purpose other than to exercise its rights and perform its obligations under or in connection with the Contract.

11.3 Entire agreement

(a) The Contract constitutes the entire agreement between the parties.

(b) Each party acknowledges that in entering into the Contract it does not rely on any statement, representation, assurance or warranty (whether made innocently or negligently) that is not set out in the Contract. Each party agrees that it shall have no claim for innocent or negligent misrepresentation or negligent misstatement based on any statement in the Contract.

11.4 Variation

No variation of this Contract shall be effective unless it is in writing and signed by the parties (or their authorised representatives).

11.5 Waiver

(a) Except as set out in clause 2.5, a waiver of any right or remedy is only effective if given in writing and shall not be deemed a waiver of any subsequent right or remedy.

(b) A delay or failure to exercise, or the single or partial exercise of, any right or remedy shall not waive that or any other right or remedy, nor shall it prevent or restrict the further exercise of that or any other right or remedy.

11.6 Severance

If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed deleted, but that shall not affect the validity and enforceability of the rest of the Contract. If any provision of the Contract is deemed deleted under this clause 11.6 the parties shall negotiate in good faith to agree a replacement provision that, to the greatest extent possible, achieves the intended commercial result of the original provision.

11.7 Notices

(a) Any notice given to a party under or in connection with the Contract shall be in writing and shall be delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company) or its principal place of business (in any other case).

(b) Any notice shall be deemed to have been received:

(i) if delivered by hand, at the time the notice is left at the proper address;

(ii) if sent by pre-paid first-class post or other next working day delivery service, at 9.00 am on the second Business Day after posting.

(c) This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.

11.8 Third party rights

The Contract does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of the Contract.

11.9 Data protection

(a) Each party shall comply with its respective obligations under all applicable data protection laws, including (where relevant) the UK General Data Protection Regulation, the Data Protection Act 2018, the EU General Data Protection Regulation, and the Privacy and Electronic Communications Regulations.

(b) Where the Supplier processes any personal data of the Customer's personnel in connection with the Contract (such as names, business contact details and order information), the Supplier shall do so as an independent controller in accordance with its privacy policy, available on the Supplier's website. Each party acts as an independent controller in respect of the personal data it processes for its own purposes under or in connection with the Contract; neither party acts as a processor for the other.

(c) Where any transfer of personal data outside the United Kingdom or the European Economic Area is required, the parties shall ensure appropriate safeguards are in place in accordance with applicable data protection laws.

11.10 Governing law

The Contract, and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation, shall be governed by and construed in accordance with the law of England and Wales.

11.11 Jurisdiction

Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.